Ordering of parts and fabrication of fountains will not begin until deposit has been received by LAKE FOUNTAINS. Delay in receipt of deposit may void agreed upon delivery date.
LAKE FOUNTAINS & AERATION, INC., hereinafter referred to as the seller, warrants all products and parts of its own manufacture against defects in material or workmanship for a period of Three (3) years from date of shipment or installation when given normal and proper usage as determined by seller upon examination, and when owned by the original user. Components purchased by seller as complete units and used as an integral part of seller’s equipment, such as, but not limited to, pumps and motors, will be covered by the standard warranty of the manufacturer thereof. Seller will repair or replace F.O.B. original shipping point any part or parts of its manufacture which, in its judgment, shall disclose defects in either material or workmanship. If requested by seller, parts for which a warranty claim is made are to be returned, transportation prepaid, to our factory, with the original proof of purchase. A return authorization number must be obtained from LAKE FOUNTAINS & AERATION, INC. prior to return. Expressly excluded from this warranty are replacement light bulbs. This warranty becomes void if article claimed to be defective has been repaired or altered in any way or when the article has been subject to misuse, negligence or accident, or when instructions for installing or operation have been disregarded.
WE MAKE NO OTHER WARRANTY, EXPRESSED OR IMPLIED AND MAKE NO WARRANTY OF MERCHANTABILITY OR OF FITNESS FOR ANY PARTICULAR PURPOSES, AND THERE ARE NO WARRANTIES WHICH EXTEND BEYOND THE DESCRIPTION ON THE FACE THEREOF. NO EMPLOYEE OR REPRESENTATIVE IS AUTHORIZED TO CHANGE THIS WARRANTY IN ANY WAY OR GRANT ANY OTHER WARRANTY. THE REMEDIES HEREIN ABOVE AFFORDED TO THE ORIGINAL USER ARE EXCLUSIVE OF ALL OTHER REMEDIES PROVIDED BY LAW. SELLER SHALL NOT BE LIABLE FOR INDIRECT OR CONSEQUENTIAL DAMAGES.
Requests for warranty work which are unjustified will be treated as a regular service call and CUSTOMER will be billed for travel, labor and materials. Examples include calls for nuisance tripping of breakers not due to fault of LAKE FOUNTAINS’ equipment and algae and silt buildup on fixture lens giving the appearance of burnt out lamps.
Electrical items supplied by LAKE FOUNTAINS including time clocks, magnetic motor starters and any other electrical devices or controls can be delivered to the CUSTOMER so that CUSTOMER’S electrical contractor may wire in these devices prior to fountain installation.
If LAKE FOUNTAINS is to perform installation of fountain, CUSTOMER shall supply the appropriate power as requested prior to installation so that LAKE FOUNTAINS can test and adjust all fountain equipment while on site. CUSTOMER shall obtain any required permits. Trenching, conduit and hookup of electrical equipment shall be performed by competent electrician retained by CUSTOMER.
Fountains which have been ordered, fabricated and are ready to install but are not accepted by CUSTOMER within 60 days of agreed delivery time will be delivered to job site with full balance due and payable. An additional charge will result if CUSTOMER later requests installation after fountain has been delivered to job site. Cancellation of fountain orders will result in forfeiture of deposit by CUSTOMER.
Due to our continuing policy of product improvement, LAKE FOUNTAINS & AERATION, INC. reserves the right to change our products and specifications without notice. All performances were measured at sea level during calm, clear weather conditions.
